For Coronavirus Acquisition-Related Information and Resources, click here.
An Official Website Of The United States Government

42.1305 Contract clauses.

My Favorites


42.1305 Contract clauses.

42.1305 Contract clauses.

      (a) The contracting officer shall insert the clause at 52.242-14, Suspension of Work, in solicitations and contracts when a fixed-price construction or architect-engineer contract is contemplated.

      (b)

(1) The contracting officer may, when contracting by negotiation, insert the clause at 52.242-15, Stop-Work Order, in solicitations and contracts for supplies, services, or research and development.

           (2) If a cost-reimbursement contract is contemplated, the contracting officer shall use the clause with its AlternateI.

      (c) The contracting officer shall insert the clause at 52.242-17, Government Delay of Work, in solicitations and contracts when a fixed-price contract is contemplated for supplies other than commercial or modified-commercial items. The clause use is optional when a fixed-price contract is contemplated for services, or for supplies that are commercial or modified-commercial items.